Terms & Conditions

By accessing this website or using any service provided by VRINDAVAN DIGITAL MARKETING PRIVATE LIMITED, you agree to comply with the terms and conditions stated below. These terms are designed to ensure clarity, transparency, and a professional working relationship with all users and clients.

Use of Our Services

Our services are intended for legitimate business, commercial, and professional purposes only. Clients are required to provide accurate information and cooperate throughout the service delivery, development, or support process.

Payment Terms

Certain services may require advance or milestone-based payments before commencement. Failure to complete payments on time may result in suspension or termination of services until dues are cleared.

Project Scope & Deliverables

All services and deliverables are executed strictly as per the mutually agreed scope of work. Any additional features, changes, or modifications requested beyond the original scope may impact pricing and delivery timelines.

Intellectual Property

All software, designs, content, code, or digital assets created during the course of a project remain the property of VRINDAVAN DIGITAL MARKETING PRIVATE LIMITED until full payment has been received. Ownership rights are transferred to the client only after complete payment settlement.

Limitation of Liability

VRINDAVAN DIGITAL MARKETING PRIVATE LIMITED shall not be liable for any indirect, incidental, or consequential losses, including loss of business, revenue, or data arising from the use or inability to use our services. We do not guarantee specific outcomes or results unless explicitly agreed in writing.

Governing Law

These terms shall be governed and interpreted in accordance with the laws of India. Any disputes arising shall be subject to the exclusive jurisdiction of the courts located in Odisha, India.